Let us look at some of the types of breach which apply in a construction. Comm whether or not there has been a repudiatory breach is highly fact sensitive: comparison with other cases is therefore of limited value. The mere fact that a party believed it was entitled to do what in law was a breach of contract does not excuse it if the breach was repudiatory.

This error was found not to be a repudiatory breach. Woodar v Wimpey demonstrates that wrongly relying on a determination provision is not necessarily a repudiatory breach. That case involved a contract of sale. Generally, however, matters are less amicable. Comm , the Defendant agreed to sell the Claimant 13 flats. The completion date passed and the Claimant serviced notice to complete, wrongly identifying the final date for completion as earlier than was correct.

That was met with silence and, when the Claimant then prematurely served notices of rescission, the Defendant argued that the Claimant was in repudiatory breach. The contractor had suspended work on the mistaken view that a payment due to it had not in fact been made.

The Court held that the arbitrator deciding the subsequent dispute had not erred in law in deciding that such a genuine mistake, which the paying party had been aware of but had not corrected, did not amount to repudiation. Stopping work to force a party to change contract terms is another matter. The contractor had not commenced work on time, had failed to proceed with the work with due diligence and was not going to finish by the completion date and had made it clear that it was not going to proceed unless the other party agreed to revised payment proposals.

In construction contracts, there are normally provisions setting out the effect of delay: usually fixing the amount on a weekly basis. The starting point therefore is that the parties have agreed what damage is likely to be suffered and a mechanism to pay it, which would indicate that delay does not go to the root of the contract. Rather, upon the innocent party electing to treat his liabilities to perform as at an end, the primary obligations of the party in breach to perform the contract are replaced by secondary obligations to pay damages for the loss arising from the breach.

References to termination in this guide are to termination in this strict sense. Here the contractual rights and obligations remain in place until the innocent party opts to rescind the contract, at which point the rescission operates to render the contract a nullity. Finally, in the following section we use the term "repudiatory breach" in its broadest sense, to encompass all common law termination grounds, and not just one of the grounds — renunciation — to which some authors confine the expression.

Each of the following constitutes a repudiatory breach of contract justifying termination at common law:. Not every breach of contract gives the innocent party the right to terminate. The innocent party will only be discharged from future performance of the contract if the term breached qualifies as a condition, i.

Provided the term is a condition, the innocent party will be entitled to terminate the contract, no matter how minor the consequences of the breach. A breach of warranty, on the other hand, does not absolve the affected party from future performance 1 , no matter how serious. The contract continues on foot, the parties remain obliged to perform their future obligations under the contract, and the only remedy for the breach is damages.

A breach of an intermediate or innominate term, i. It must "go to the root of the contract", "frustrate the commercial purpose" of the contract or "deprive the party not in default of substantially the whole benefit" 3 of the contract. In every case, the court will look at the nature and consequences of the breach to decide whether termination is justified. Deciding whether a term of a contract is a condition, warranty or intermediate term is not always straightforward.

In some cases, statute may dictate or influence the classification. For example, certain provisions in the Sale of Goods Act specify whether certain terms should be regarded as conditions or warranties. The courts will also pay regard to the express terms of a contract: if the parties expressly identify a term as a condition or warranty, the courts will generally treat it as such. However, there are exceptions such as where statute provides otherwise or where, in the circumstances, the court considers that the parties cannot have intended a breach of that term to result in automatic termination.

In those cases, the courts usually construe the term as being intermediate and look to the surrounding circumstances to ascertain whether the breach is sufficiently serious to justify termination. If the parties intend any breach of a particular term to give rise to automatic termination, the contract should make that clear. Where time is of the essence in a contract, even a short delay can trigger a common law right to terminate for breach as the term is considered a condition of the contract.

Where a party declares an unequivocal intention to abandon further performance of the contract, or an intention not to perform some essential aspect of the contract, the innocent party is entitled to treat himself as discharged from further performance.

Not every declaration of non-performance is a repudiatory breach. Sometimes a party will refuse to perform some, rather than all, of its contractual obligations or indicates that he will only perform them in a particular manner.

In determining whether the breach is repudiatory the court will consider whether the non-performance amounts to a breach of condition or deprives the innocent party of substantially the whole benefit of the contract see below. A declaration of non-performance can be either an express refusal to perform or it can be inferred from the party's conduct if he behaves in a manner which would lead a reasonable person to conclude that he has no intention of fulfilling his obligations.

Termination is not automatic. The innocent party may elect either to accept the breach and treat the contract as discharged or to affirm the contract and press the party in breach to perform. The law does not lay down a particular period in which the election must be made.

In practice this area can be fraught with difficulty because, while the innocent party is deciding how to treat the contract, he risks taking a step which constitutes an election to affirm it and, once an affirmation has been made, it cannot be revoked.

Commercial contracts often contain express termination clauses which provide for termination in certain specified circumstances, including for breaches other than repudiatory breaches. Some contractual termination clauses work by expressly classifying terms as conditions or warranties so as to make clear those circumstances in which the contract can be brought to an end and those which only give a right to claim damages.

Some contractual provisions attempt to give rights to terminate for "material" or "substantial" breaches, for "any" breaches however minor or for repeated breaches. Contractual termination rights will operate in addition to common law rights to terminate unless the latter are expressly or impliedly excluded 17 by providing that the contract may only be terminated by exercising the contractual rights.

Termination clauses require careful drafting and regard must be had to the way in which the courts approach such provisions. However, electing to terminate a contract on the basis of a contractual termination right can preclude a common law claim for future loss of bargain as a result of a repudiatory breach see below.

Serious consideration needs to be given whenever a party is exercising contractual termination rights. Deciding whether you have a right to terminate a contract and how to bring about that termination can be difficult. The compensation that can be claimed by way of damages can vary depending on which termination rights are exercised. Damages for repudiatory breach are assessed according to normal principles.

This means that the innocent party is, as far as possible, put in the position in which it would have been if the contract had been properly performed, subject to the usual rules on causation, forseeability and mitigation.

At common law, in addition to claiming recompense for losses resulting from the breach or breaches prior to the termination, an innocent party accepting a repudiatory breach of contract is entitled to claim "loss of bargain" damages an amount to compensate for the lost opportunity to receive future performance of the contract.

Contractual provisions may entitle a party to terminate where the breach in question does not amount to a repudiatory breach at common law. However, in this situation it may not be possible to recover "loss of bargain" damages.

Where the breach is not also repudiatory at common law, damages will usually be limited to loss suffered up to the date of termination unless the contract expressly provides otherwise. The difference can be considerable. Where a party has both common law and contractual rights to terminate, but elects to terminate using a contractual termination entitlement rather than alleging repudiatory breach, it will be prevented from claiming loss of future bargain damages. An innocent party who instead decides to affirm the contract , rather than terminating, can claim damages in the normal way for loss suffered as a result of the breach or breaches.

Before terminating a contract, consider whether you want the relationship to end or whether you should continue with the contract but reserve the right to claim damages for any breach. You may want to renegotiate the contract. If you decide to terminate, you should also check whether there is a prescribed dispute resolution procedure to reach a solution and whether the party in default has a contractual right to remedy the breach within a certain period.

Although an election to terminate need not be made immediately, you should be careful not to take too long or engage in conduct which could be seen as an affirmation of the contract. Take care to qualify any correspondence with appropriate reservations of rights when engaging in further business related conduct. Once communicated, an election to terminate cannot be withdrawn without the other party's consent. If a contract is terminated but the parties proceed for a time on "business as usual" terms, a new or supplementary contract might be created, potentially on the same terms as previously, which could be a commercially undesirable outcome.

The decision to terminate, and how you communicate that decision, can become more complicated where a party has both contractual and common law rights to terminate. The consequences of this choice can be significant. You are, in effect, saying: 1. If C contract has F fraud then it is V void. All C contracts contain P or L. Therefore all C have F 6. Therefore all C are V. Point 1 may be true, but perhaps not always. Points 2 and 3 are not necessarily true, and point 4 is not true.

It follows that point 5 is not true and point 6 is not true. Thanks Mark for this very informative article. I still have one nagging question however: can we distinguish in English between a contract terminating by coming to its natural conclusion the expiry of the contract and a contract being terminated for breach?

Interestingly, there are some articles that discuss the difference between the expiry of a contract and its termination e. Some people regard expiry of a contract as different from termination. My personal view is that this is tiresome. You are commenting using your WordPress. You are commenting using your Google account.

You are commenting using your Twitter account. You are commenting using your Facebook account. Notify me of new comments via email. Notify me of new posts via email. This site uses Akismet to reduce spam. Learn how your comment data is processed.

Find us at www. Enter your email address to subscribe to this blog and receive notifications of new posts by email. Email Address:. Sign me up! RSS - Posts. RSS - Comments. This site is hosted by Wordpress. Rescission can also take place by mutual agreement of the parties. However, rescission is not a remedy for a breach of contract. Repudiation, anticipatory repudiation or anticipatory breach is a declaration made by a contractual party, verbal or by conduct, that they are not willing, or unable to, perform their obligations under the contract.

Repudiation stop future performance of contract obligations. However, unlike rescission, rights already given to the parties remain valid.